Terms & Conditions

By purchasing a design package with Merritt Design Co. you agree to the following terms:

Welcome to Merritt Design Co. By accessing or using our services, you agree to comply with and be bound by the following terms and conditions.


Scope of Services

We offer a range of interior design services, including but not limited to:

  • Full-Service Interior Design

  • Design-Only Consultations

  • Vacation rental and boutique hotel design

Specific services will be detailed in individual client agreements.


Client Responsibilities

Clients are expected to:

  • Provide accurate information regarding project requirements.

  • Ensure timely decisions to facilitate project schedules.

  • Grant access to premises as needed for project completion.


Payments and Fees

Payment terms are as follows:

  • An initial deposit is required to commence work.

  • Payment terms  will be outlined in the client agreement.

  • Late payments may incur additional fees.


Use of Third-Party Contractors

For projects involving construction or remodeling, we work exclusively with licensed general contractors (GCs). While we provide project management to ensure design execution and coordination, the GC is responsible for hiring and managing subcontractors, vendors, and construction timelines. Clients hire the contractor directly, and we can provide referrals based on the scope of work.


Intellectual Property

All design concepts, drawings, and materials provided by Merritt Design Co. remain our intellectual property unless otherwise agreed upon in writing. Clients are granted a license to use these materials for their intended purpose only.


Limitation of Liability

Merritt Design Co. is not liable for:

  • Delays caused by third-party contractors or suppliers.

  • Material defects or issues beyond our control.

  • Any indirect or consequential damages arising from our services.


Termination

Either party may terminate the agreement with written notice. Clients are responsible for payment of all services rendered up to the termination date.


Governing Law

These terms are governed by the laws of the State of Florida. Any disputes arising shall be resolved in the courts of Broward County, Florida.


Amendments

Merritt Design Co. reserves the right to amend these terms at any time. Clients will be notified of significant changes.

Contact Us

If you have any questions about these terms, please contact us at info@merrittdesignco.com.